Archive

Performed claims analysis, construction oversight, contract administration, and expert testimony for a surety involved in the mechanical installations on a prison project.

Analyzed detailed as-planned and as-built schedules for two state prison projects and a city prison project.

Prepared a contractor’s $250,000 change request for delay and disruption associated with structural, mechanical, and electrical design changes in the construction of a correctional facility.

Prepared an expert report regarding disputed change orders, delay, and project management performance on an expansion of a county jail.

Prepared a damage and schedule analysis on behalf of a general contractor for a $560,000 claim on a new cafeteria building and dormitory renovation project at a youth detention facility in Okeechobee. Was designated as a CPM expert witness for the jury trial and presented preliminary findings at the court-ordered mediation that resulted in a successful settlement.

Prepared an electrical subcontractor’s claim for delays, extra work, and loss of productivity on the installation of fire alarm, security, and communication systems for the Federal Bureau of Prisons Project in Beaumont. The contractor’s increased costs resulted from delays, changes, field work orders, rework, loss of productivity, and acceleration to the Division 17 installation work. Prepared an expert report, and assisted counsel in the defense of the opposing expert’s deposition, which resulted in a successful settlement of the dispute.