On behalf of a construction manager, analyzed a mechanical contractor’s contract and quantum meruit claim for disputed changes in scope, delays, and loss of productivity on the installation of piping systems on a computer microchip manufacturing facility. Presented testimony in arbitration.

Prepared an electrical contractor’s claim involving engineering delay, errors and omissions resulting in workarounds and construction delays on the installation of life safety systems and instrumentation and control automation on a silicone chip plant and cleanroom facility in Colorado Springs. Performed a schedule analysis of delay impacts due to engineering rework and added change order work, causing schedule compression and acceleration with trade stacking, overmanning of crews with a shortage of qualified labor causing productivity loss due to overtime fatigue, lack of coordinated drawings, late material delivery, and substandard supervisory management and cost controls by the construction manager.