Gas, Gasification, GTL, LNG, and NGL

On behalf of an owner seeking to recover hundreds of millions of dollars in delay and disruption costs paid to an EPC contractor on an LNG plant, performed the following scope of work: 1) critique of the contractor’s compliance with industry practices in the preparation and updating of the project baseline CPM schedule and schedule updates; 2) preparation of a windows-based schedule delay analysis to quantify delays on the critical and near-critical paths; 3) assessment of delay, disruption, and project management performance issues by the EPC contractor; and 4) quantification of delay and disruption damages incurred by the subcontractors in the construction of the facility. Prepared an expert report to be submitted as part of arbitration proceedings.